论文部分内容阅读
某建筑公司与开发公司签订了一宗工程承包合同,合同工期为280天,工程造价为750万元,后因设计图纸变更、工程量增加和开发公司未按合同的约定支付工程进度款等原因,致使工期延误了1000多天,开发公司也在工程款支付到605万元以后,拒绝支付余下的工程款和变更图纸后新增加工程的工程款共245万元。为此建筑公司将开发公司告上了法院,要求支付拖欠的工程款和逾期付款的违约金以及停工损失等共286万元。
A construction company and development company signed a contract for the project, the contract period of 280 days, the project cost of 7.5 million yuan, due to changes in the design drawings, engineering and development companies have not agreed to pay the progress of the contract and other reasons , Resulting in a delay of more than 1,000 days, the development company is also paid 6.05 million yuan in engineering payments, refuse to pay the remaining construction funds and change the drawings after the new construction project added a total of 2.45 million yuan. To this end, the construction company sued the development company for the court, demanding payment of a total of 2.86 million yuan in arrears of construction funds and liquidated damages, as well as suspension losses.